KAISER ALUMINUM & CHEMICAL SALES, INC., Plaintiff-Appellant, v. PPG INDUSTRIES, INC., Defendant-Appellee, 42 F.3d 1147

ALARCON, Senior Circuit Judge. Midwest Curtainwalls (“Midwest”) sued Kaiser Aluminum (“Kaiser”) for damages resulting from the delay in erecting a curtain-wall facade due to Kaiser’s untimely delivery of painted aluminum extrusions. Kaiser settled with Midwest for $500,000. Kaiser then brought this diversity action against PPG Industries (“PPG”) seeking reimbursement for the settlement and attorneys’ fees associated with the Midwest action.

Kaiser alleged that the untimely performance of its contractual duties with Midwest was due to delays resulting from extra efforts it was forced to expend to remedy problems related to the defective paint provided to its subcontractor, Krestco, by PPG. Kaiser sued PPG under theories of implied breach of warranty (Count I), and common law indemnity (Count II). The district court, relying on Texas law, granted

summary judgment for PPG on both counts. The district court ruled that Texas law did not allow Kaiser to recover the settlement amount and attorneys’ fees from PPG. The court entered its final judgment on December 8, 1993. We have jurisdiction pursuant to 28 U.S.C. § 1291. We affirm because we conclude that settlement and fee expenses cannot be recovered as consequential damages under Texas law. I. BACKGROUND This action arose from a dispute relating to the construction of the Bank One office tower in Indianapolis, Indiana.

Midwest entered into a contract to provide curtainwall panels for use on the exterior facade of the building. Kaiser agreed to provide approximately one million pounds of aluminum extrusion product to Midwest for use in fabricating the curtainwall panels. The extrusions were to be coated with paint manufactured by PPG. Because Kaiser lacked the capacity to apply PPG’s paint, it hired Krestco to paint the materials and ship them directly to Midwest.

Although Kaiser representatives met with representatives from PPG to review and approve the paint, and later communicated regarding the paint problems which developed, Kaiser and PPG had no written contract. Krestco ordered and purchased the paint from PPG. Kaiser neither purchased nor came into possession of the paint. By late July 1988, Krestco painted and shipped five truckloads of Kaiser’s aluminum extrusions to Midwest. Shortly thereafter, Midwest contacted Kaiser to report that the paint on the extrusions was defective. Midwest complained that there was “trash” in the paint.

It rejected a portion of the extrusions. Due to the problems with the paint, Krest-co informed Kaiser that it would no longer perform its contract with Kaiser. Kaiser replaced Krestco with a new subcontractor, Western Extrusions. Western Extrusions agreed to expedite the painting of the material. Kaiser rearranged its production

schedule and re-extruded new material so that Midwest would be adequately supplied with extrusions with only a limited delay. As a result of the delay, erection of the curtain-wall was not completed on schedule. Midwest filed a diversity action against Kaiser in the United States District Court for the Northern District of Ohio for damages resulting from the delay. Kaiser notified PPG of the action, but did not join PPG as a third-party defendant. Kaiser settled the action filed by Midwest for $500,000.

Kaiser then brought this diversity action against PPG seeking “reimbursement of the principal amount paid by Kaiser in settlement of the Midwest Lawsuit, [and $250,000 in] costs incurred in defending the Midwest Lawsuit, including attorneys’ ... fees.” Kaiser alleged that its untimely performance with Midwest was directly attributable to PPG’s defective paint. Kaiser sued under theories of implied breach of warranty (Count I), and common law indemnity (Count II).

Prior to the date set for trial, PPG filed three motions in limine seeking to exclude evidence proffered by Kaiser relating to the amount and reasonableness of the settlement it paid to Midwest. PPG argued that this evidence should not be admitted at trial because, under Texas law, the settlement and fees were not recoverable as consequential damages.

Kaiser did not file a brief in response, but submitted to the district court copies of pertinent Texas Business and Professions Code sections, as well as eases and other materials regarding the issue whether the settlement and fees were recoverable as consequential damages for a breach of implied warranty. The district court granted PPG’s motions, thus effectively precluding Kaiser from offering any evidence relating to the settlement and fee amounts.

The court then vacated the date set at that time for trial “to allow Kaiser additional time to develop evidence, if any, regarding other consequential damages it may claim which were proximately caused by PPG’s alleged breach.” Kaiser, however, advised the court that it intended to limit its damages solely to the settlement and fees. Ultimately, the district court granted

summary judgment for PPG on both counts of Kaiser’s complaint. The district court held that, under' Texas law, the amount paid in settlement of an action and the costs of defense were not recoverable as consequential damages. Kaiser argues before this court that its “suit for breach of warranty and its claims for damages are clearly supported by Texas law and the Uniform Commercial Code ... [and that on] that basis, ... the recovery of settlement amounts and costs ... is clearly permitted.” II. ANALYSIS We review de novo a district court’s decision to grant

summary judgment. Karazanos v. Navistar Int’l Transp. Corp., 948 F.2d 332, 335 (7th Cir.1991). In conducting this review, we draw all reasonable inferences in the light most favorable to the nonmoving party. Lohorn v. Michal, 913 F.2d 327, 331 (7th Cir.1990).

Summary judgment is appropriate when there are no genuine issues as to any material fact and the moving party is entitled to judgment as a matter of law. Fed.R.Civ.P. 56(e). A. Count I: Implied Breach of Warranty In Count I, Kaiser prayed for “reimbursement of the principal amount paid by Kaiser in settlement of the Midwest Lawsuit, [and $250,000 in] costs incurred in defending the Midwest Lawsuit, including attorneys’ ... fees.” Under Texas law, the procedure for obtaining such reimbursement is by “vouching in” the third party to the action at issue. Tex.Bus. & Comm.Code § 2.607.

The voucher method may not be invoked, however, when the underlying action was settled instead of fully litigated to judgment. CGM Valve Co. v. Gulfstream Steel Corp., 596 S.W.2d 161, 163 (Tex.App.1980). Apparently recognizing this bar, Kaiser adopted a novel approach in an attempt to recover the amount of the settlement and its legal costs. Kaiser labeled the settlement and legal costs “consequential damages” and sought to recover under Texas Business and Commercial Code sections 2.714 and 2.715 for breach of warranty. Tex.Bus. & Comm. Code §§ 2.714, 2.715.

The district court rejected this attempt, stating that Texas authority did not support Kaiser’s argument that it could recover such expenses as consequential damages. We agree. The precise question presented has not been ruled upon by the Texas Supreme Court. Texas has, however, expressed a policy against allowing parties to recover, in a voucher proceeding, the amount paid in other actions because settlements do not result from “full dress, arm’s length, good faith, adversary proeeeding[s].” CGM Valve, 596 S.W.2d at 163 (internal quotation omitted).

Rather, the settlement is likely to be “agreed upon without vigorous contest or the best effort of both litigants.” Id. at 164. For this reason, in CGM Valve, the Court of Civil Appeals of Texas reversed the judgment in a common law indemnity action granting the plaintiff as damages the amount of its settlement from litigation with a third party. Id. The rationale employed by the court in CGM Valve applies to the issue before this court.

We are persuaded that the Texas Supreme Court would not permit Kaiser to circumvent the rule announced in CGM Valve by recovering as consequential damages what it would not be able to recover through the voucher procedure. Kaiser contends, however, that Texas’ breach of warranty provisions are based upon the Uniform Commercial Code and should be interpreted in conformance with similarly worded statutory provisions in other jurisdictions and the purposes of the UCC.

Kaiser cites several cases to support its position that the amount paid in settlement of an action and the attendant legal costs are recoverable under the Texas Business and Commercial Code. Kaiser’s reliance on the cited .authority is misplaced. Each case is readily distinguishable. In two of the cases cited by Kaiser, Chemco Industrial Applicators Co. v. E.I. du Pont de Nemours & Co., 366 F.Supp. 278 (E.D.Mo.1973), and Safeway Stores, Inc. v.

Schreiber Cheese Co., 326 F.Supp. 504 (W.D.Mo.1971), rev’d, 457 F.2d 962 (8th Cir.1972), the plaintiffs sought reimbursement for judgments obtained against them in prior litigation. Chemco, 366 F.Supp. at 281-83; Safeway, 326 F.Supp. at 509. Neither case involved a settlement. Thus, they are not relevant to the issue we must decide. Guy James Construction Co. v. Trinity Industries, Inc., 462 F.Supp. 252 (N.D.Tex. 1978), aff'd in part and rev’d in part, 644 F.2d 525 (5th Cir.1981), and Polidori v. Kordys, Puzio & Di Tomasso, 217 N.J.Super. 424, 526 A.2d 230 (1987), do not support Kaiser’s argument.

In each ease, the court held that the plaintiff could recover settlement expenses from prior litigation as consequential damages in a breach of contract action against the defendant. Guy James, 462 F.Supp. at 257; Polidori, 526 A.2d at 235-36. No contract existed between Kaiser and PPG. Kaiser’s action is based on a breach of implied warranty under the UCC. Kaiser’s reliance on Wood v. Component Construction Corp., 722 S.W.2d 439 (Tex. App.1986) is equally unpersuasive.

In Wood, the court held the consequential damages caused by the defendant’s breach of implied warranty could be established by evidence of the settlement amount the plaintiff incurred in prior litigation. Id. at 445-16. However, Wood involved a claim filed under the Texas Deceptive Trade Practices Act, not a claim for implied breach of warranty under Texas’ version of the UCC. Id. at 446. Kaiser also refers us to Certain-Teed Products Corp. v. Goslee Roofing & Sheet Metal, Inc., 26 Md.App. 452, 339 A.2d 302 (1975); Woodbury Chemical Co. v. Holgerson, 439 F.2d 1052 (10th Cir.1971); Texsun Feedyards, Inc. v.

Ralston Purina Co., 311 F.Supp. 644 (N.D.Tex.1970), aff'd in part and rev’d in part, 447 F.2d 660 (5th Cir.1971), and Step-Saver Data Systems, Inc. v. Wyse Technology, 912 F.2d 643 (3d Cir.1990). They do not further Kaiser’s cause. In each of these cases, the plaintiffs introduced evidence of the actual injury they suffered as a result of the defendants’ conduct. The plaintiffs submitted evidence regarding the expenses they incurred reroofing several buildings (Certain-Teed) and reapplying an herbicide (Woodbury) when defective materials supplied by the defendants negatively affected the original work.

Certain-Teed, 339 A.2d at 302; Woodbury, 439 F.2d at 1053. Texsun and Step-Saver involved the recovery of actual commercial losses. In Texsun, the plaintiff recovered as consequential damages business expenses it incurred as a result of the defendant’s breach. Texsun, 311 F.Supp. at 645. In Step-Saver, the plaintiff sought to recover expenses incurred replacing the defendant’s defective computer components in an attempt to maintain its customers’ goodwill. Step-Saver, 912 F.2d at 652. In neither case did the plaintiff seek to recover the amount paid in settlement in prior litigation.

Similarly, in Nezperce Storage Co. v. Zenner, 105 Idaho 464, 670 P.2d 871 (1983), cited by the' dissent, the plaintiff wheat purchaser was allowed to recover from the defendant wheat seller the expenses the plaintiff incurred when the wheat proved unsuitable and the plaintiff was forced to reimburse his customers for damages they suffered from planting defective seed. Id. at 874. i The plaintiff in Nezperce introduced evidence of the actual injury it suffered as the result of the defendant’s conduct, not the amount of a settlement it paid to a third party in previous litigation.

The dissent also cites City Welding & Manufacturing Co. v. Gidley-Eschenheimer Corp., 16 Mass.App.Ct. 372, 451 N.E.2d 734 (1983). In City Welding, the Appeals Court of Massachusetts ruled that it was proper to admit as evidence of consequential damages a judgment obtained against the plaintiff in prior litigation. Id. 451 N.E.2d at 737. By contrast, Kaiser intends to rely upon the amount of a settlement it paid to establish its consequential damages.

Because this settlement did not result from a “full dress ... adversary proceeding,” CGM Valve, 596 S.W.2d at 163 (internal quotation omitted), we believe the Texas Supreme Court would conclude that it cannot be used to demonstrate consequential damages. Curiously, Kaiser also relies upon Stewart & Foulke, Inc. v. Robertshaw Controls Co., 397 F.2d 971 (5th Cir.1968).

In Stewart, the Fifth Circuit held that a judgment entered after settlement did not result from a “full dress, arm’s length, good faith, adversary proceeding,” and ruled that those litigation expenses were therefore not recoverable under a theory of breach of implied warranty. Id. at 973-74 (internal quotation omitted). Under the rationale of Stewart, the settlement without judgment that concluded the litigation between Kaiser and Midwest would also be nonreeoverable through a breach of implied warranty action.

The dissent cites the Restatement of Contracts in support of the proposition that Kaiser may recover its settlement expenses in this action. The dissent neglects to note, however, that the comment quoted begins with the statement “Sometimes a breach of contract results in claims by third persons against the injured party.” Restatement (Second) of Contracts § 351 cmt. c (1981).

The Restatement goes on to state, in the passage quoted by the dissent, that parties found in breach of contract may be held liable for any judgment, settlement, or litigation expenses incurred by the injured party as a result of the breach. As noted above, there was no contract between Kaiser and PPG. This action is premised upon an implied breach of warranty, not a breach of contract. Given the absence of any relevant authority to the contrary, we must adhere to the principles announced in CGM Valve. They cut against Kaiser’s theory that it can recover its settlement expenses from PPG.

Kaiser’s argument that it is entitled to recover the attorneys’ fees incurred in settling the Midwest action is contrary to Texas law. “In Texas, attorneys’ fees expended in prior litigation with third parties are not recoverable as damages: attorneys’ fees are only recoverable when provided for by contract or by agreement between the parties.” Peterson v. Dean Witter Reynolds, Inc., 805 S.W.2d 541, 549 (Tex.App.1991). B. Count II: Indemnity The district court granted PPG’s motion for

summary judgment on the indemnity count on the basis that “Texas law does not afford Kaiser an implicit right to indemnification from PPG.” Kaiser contends this was error. We disagree. “There are two basic categories of indemnity under Texas law — common law and contractual.” Hardy v. Gulf Oil Corp., 949 F.2d 826, 880 (5th Cir.1992). Because no contract for indemnity exists between Kaiser and PPG, Kaiser’s indemnity claim must be established under common law.

The situations in which an action for common law indemnity may be maintained under Texas law are “extremely limited.” Id. (citing Cypress Creek Utility Serv. Co. v. Muller, 640 S.W.2d 860, 864 (Tex.1982)). Texas common law indemnity principles may only be invoked in the contexts of agency or surety, American Alloy Steel, Inc. v. Armco, Inc., 777 S.W.2d 173, 175 (Tex.App.1989), or in two special classes of tort-based actions: (1) in product liability cases to protect an innocent retailer in the chain of distribution of the defective product, Duncan v.

Cessna Aircraft Co., 665 S.W.2d 414, 432 (Tex.1984), and (2) in negligence actions to protect a defendant whose liability is vicarious in nature, Aviation Office of America, Inc. v. Alexander & Alexander, Inc., 751 S.W.2d 179, 180 (Tex.1988). Kaiser failed to present evidence demonstrating that it fell within any of these narrow categories. Kaiser contends that its evidence that PPG’s paint was defective and that it interacted with PPG representatives presented a genuine issue as to whether it qualified as an innocent retailer in the chain of distribution. The factual record does not support this proposition.

Kaiser’s interaction with PPG did not place it in the chain of distribution of the defective paint. The paint was purchased by Krestco and Western Extrusions, not Kaiser. Moreover, the “innocent retailer” exception to the rule circumscribing the availability of common law indemnity applies in product liability cases. This is not a tort action. AFFIRMED. .

Section 2.607 provides: (

e) Where the buyer is sued for breach of warranty or other obligation for which his seller is answerable over (1) he may give his seller written notice of the litigation. If the notice states that the seller may come in and defend and that if the seller does not do so he will be bound in any action against him by his buyer by any determination of fact common to the two litigations, then unless the seller after seasonable receipt of the notice does come in and defend he is so bound. Tex.Bus. & Comm.Code § 2.607(e).